DOWNLOAD AGREEMENTS

Pedowitz Machinery Movers

Milford, CT. Lebanon, NJ. Branchburg, NJ. Copiague, NY. Pompano Beach, FL. Wilson, NC. Conroe, TX.

Unless otherwise stated in the Contractor’s Proposal, the following standard terms and conditions shall apply:

Pedowitz Standard Terms and Conditions Applicable to All Agreements.

  1. Contractor’s quotation is subject to acceptance within thirty (30) days and is conditional upon satisfactory arrangements being made with respect to payment and/or security.

  2. Standard Terms for all approved accounts are Net 30 days. Long term projects require progressive payments, and each payment is due upon receipt of invoice. C.O.D. or Due Upon Receipt is applicable for project Terms when no credit history has been established. Interest at 1.5% per month will be charged on all overdue accounts. All quotes are in US Dollars unless otherwise stated.

3. Any and all payments (Cash, Check, Credit Card or Wire) due are to be paid only to Pedowitz Machinery Movers, Inc. 1765 Express Drive North Hauppauge, NY 11788. PH 718-923-1862

4. This quotation will be limited to the scope of work detailed in Contractor’s Proposal.

5. Contractor shall not be responsible for any direct or indirect damages whatsoever caused by delays, and without limiting the generality of the foregoing, Contractor shall not be responsible for any damages or loss due to delays caused by fires, strikes, adverse weather conditions, labor disputes, material procurement difficulties, governmental regulations, accidents (without regard to cause), transportation delays or damages that are incurred during transit of said items, machinery, E.T.C or any other delay beyond Contractor’s control.

6. In the event that Contractor is delayed in the performance of the work due to the fault of Customer, its employees, servants, agents, outside (Third Party Carriers) or contractors of the purchaser other than Contractor, Contractor shall be entitled to be reimbursed for any costs it incurs as a result of any such delay. Time and Material rates for labor and equipment shall apply. This quotation shall be subject to availability of appropriate equipment.

7. In no event shall Contractor be liable for consequential damages of any nature whatsoever suffered by Customer, including but not limited to loss of use or profits due to damages to Customer’s property (real or personal) directly or indirectly arising out of Contractor’s negligent or non-negligent acts, errors or omissions.

8. Contractor’s liability for loss or damage to Customer’s property (real or personal) due to Contractor’s negligent acts, errors or omissions shall be limited to the lesser of Customer’s actual damages or Five Million Dollars ($5,000,000) General Liability, One Million Dollars ($1,000,000) Inland Marine, One Million Dollars ($1,000,000) Cargo Liability. Further, Customer agrees to indemnify and hold harmless Contractor for any damages or loss suffered by Contractor or claimed by any other person, entity or insurer in excess of any available insurance applicable to Contractor for Customer’s losses or damages due to Contractor’s acts, errors or omissions.

9. NEW YORK INDEMNIFICATION. It is the parties intent that this provision is specifically in compliance with all NEW YORK laws, and to the fullest extent permitted by NEW YORK law, customer agrees to indemnify, release, and save contractor, its employees and agents harmless from all claims or loss, (1) for death or injury to persons including contractors employees, and (2) Damage or injury to property arising in any manner out of customers actions or omissions in furtherance of the purposes of this contract or otherwise. It is the parties intent that this duty to indemnify is as broad as permitted by New York law and includes indemnification of contractor pursuant to New York labor law (200), (240) and (241). Customer agrees to indemnify and save contractor, its employees, for loss, damage or injury to property and for any claims or losses against contractor under or pursuant to New York Labor Law (200), (240) AND (241). Customers duty to indemnify shall include costs and/or expenses, including all court and/or arbitration costs, filing fees, attorney fees and costs of settlement, incurred by Contractor. Costs and expenses shall also include, but not limited to, all court and/or arbitration costs, filing fees, attorneys fees, incurred by lessor in the enforcement of this provision. Customer shall not be required to indemnify contractor for its own negligence. Customers partial indemnification obligation shall not be limited, in any way, by any limitation on the amount or type of damage, compensation, or benefits payable by or for the contractor under workers compensation acts, disability benefit acts, or other employee benefit acts. This partial indemnification provision shall only apply to the fullest extent permitted by New York law. Customers obligations shall not be limited by the amount of its liability insurance, and the purchase of such insurance shall not operate to waive any of customers obligations. This provision is separate and distinct from any other provision in this contract, including any provision concerning indemnification and procurement of insurance. If this provision, or any part thereof, is declared invalid, then all other provisions ot this agreement, shall stand.

10. At Customer’s sole cost and expense, and upon written request by Customer, Contractor shall attempt to obtain additional insurance coverage for the Scope of Work in excess of the above stated limit of liability provided:

  1. the request is signed by an authorized representative of Customer;

  2. the request confirms Customer’s agreement to pay for such insurance;

  3. the requested insurance is at least equal to the Declared Value;

  4. the request is made at least ten (10) days prior to commencement of performance of the work set forth herein;

  5. the insurance requested is reasonably obtainable by Contractor; and

  6. unless specifically requested by Customer in writing, any such insurance shall not cover Customer’s consequential damages in the event of loss or “loss due to environmental hazard,” nor will it

  7. Supersede Contractor’s LIMITATION OF LIABILITY or Customer’s duty to indemnify stated above except to the extent of available additional insurance.

11. Prices are subject to the Customer providing Contractor with access, ample room and suitable ground conditions to perform the work agreed to in the Scope of Work. Access shall include removal of any obstacles and/or utilities as required by Contractor.

a. Contractor’s bid is based upon working straight-time hours only, except where dictated by scope of work, DOT restrictions, etc. Where work is required to be performed because of conditions beyond the control of Contractor, after normal working hours, and any time on Saturday or Sunday, and holidays, an additional charge will be made to cover the cost of overtime paid to workers and/or cost for travel time and layover for legal holidays and weekends.

12. Where Applicable Contractor’s price is based on a designated number of hours for dismantling, loading, transportation, unloading and reassembly of equipment. Any demurrage charges (through no fault of Contractor) shall be the responsibility of the Customer.

13. All federal, state or municipal taxes or licenses or any taxes or licenses imposed on or applicable to the transaction herein by any taxing authority are extra and chargeable to Customer.

14. Contractor’s price is based on the weight(s) and dimensions provided by Customer. The price is subject to change should any of the dimensions or weight(s) vary from those provided by Customer.

15. All third party charges that Contractor is required to pay will be charged at Contractor’s cost plus 20%.

16. Free and clear access to all work areas must be provided by Customer. Time spent by Contractor to clear the work area or to gain access to install or remove equipment will constitute additional labor and material above the bid price.

17. All surfaces over which Contractor’s equipment must pass, either loaded or unloaded, must accommodate projected weights. Customer has been consulted on such weights, has verified bearing capacity of all surfaces for Contractor’s work. Any damage to surfaces, sub-surfaces or utilities due to a failure to accommodate loaded or unloaded weights of Contractor’s equipment shall be solely for the account of Customer.

I. Standard Terms and Conditions Applicable to Specialized Heavy Haul & Rigging

  1. Others will provide the following (unless otherwise noted on Proposal):

    • 􏰀  Charges incurred from the region’s State Patrol for weighing and measuring loads. Note: Not all loads are weighed and measured. The DOT selects loads at random or based on super load status, it is State Patrol policy to now charge the trucking company for their labor and benefits to weigh and measure loads for the DOT.

    • 􏰀  Clear access to all work areas and adequate staging areas.

    • 􏰀  Security.

    • 􏰀  Any necessary civil work.

    • 􏰀  Road plate, gravel, etc., for adequate ground loading.

    • 􏰀  Ocean Freight, Water Crane/Barge and/or Rail including rail siding usage fees.

    • 􏰀  Vessel discharging, Port Fees, Heavy Lift Charges, Customs Clearance, Shadow

      Labor, Etc.

    • 􏰀  Project site clearance and/or Badging.

    • 􏰀  Structural (Bridge) Analysis or Surveys (Engineering) required by local jurisdictions for route clearance. Lifting and/or removal and reinstallation of utility wires for route clearance.

    • 􏰀  Accurate layout for equipment positioning.

    • 􏰀  All electrical work.

    • 􏰀  Removal, disposal and refilling of all fluids and/or hazardous materials.

    • 􏰀  All foundation work and associated hardware, anchoring, leveling and/or alignments.

    • 􏰀  Handling of all items not listed in the “scope of work.”

    • 􏰀  Any necessary modifications and/or upgrades.

    • 􏰀  All overtime and shift differential.

    • 􏰀  All applicable taxes.

    • 􏰀  Any necessary permits associated with land use, construction, electrical, etc.

  2. All Estimates are based on the following conditions (Unless otherwise noted on Proposal):

    • 􏰀  Site unseen conditions.

    • 􏰀  Adequate weather conditions.

    • 􏰀  Weights and dimensions provided.

    • 􏰀  Pending Route Survey.

    • 􏰀  Route clearance and permit approval by all county, city and state agencies.

    • 􏰀  Current Highway restrictions (DOT, Construction, Weather, etc.)

    • 􏰀  The estimate provided makes no guarantees of acceptance or permit approval by the county, city and/or state agencies (Bridge Department / Pavement Department, etc.).

    • 􏰀  Any standby time and/or fees accrued due to causes beyond Pedowitz control will be invoiced at our current Time & Material rates. This includes delays caused by weather, transportation by others, vessel/rail car delivery and/or schedule changes that impact other scheduled projects.

    • 􏰀  Subject to Equipment and Manpower availability.

Machinery Movers-Warehousing-Export Packing & Crating-Legal & Oversize Transportation.

Standard Terms and Conditions Applicable to Storage of Customer Property

20. Tender for Storage. All goods for storage shall be delivered at the Warehouse properly marked and packed for handling. Customer or Customer’s agent shall furnish at or prior to such delivery a manifest showing marks, brands or sizes to be kept and accounted for separately, and the class of storage desired.

21. Storage Period and Charges. All goods are stored on a month-to-month basis. Unless otherwise provided, a storage month shall extend from a date in one calendar month to but not including the same date of the next and all succeeding calendar months. All charges for storage are per package or other agreed unit per month. Unless otherwise agreed upon, storage for a period of less than thirty (30) days shall result in a charge of not less than $100. Storage will then be charged by square footage, multiplied by the square footage rate per month, plus 20% aisle space. Storage shipped after the first (1st) of the month will be invoiced to the fifteenth (15th) of the month. Storage shipped after the fifteenth (15th) of the month will invoice to the end of the month. Interest calculated at a rate of 1.5% per month shall be added to all late and/or unpaid charges.

22. Transfer, Termination of Storage, Removal of Goods. Instruction to transfer goods on the books of Contractor are not effective until delivered to and accepted by Contractor, and all charges up to the time transfer is made are chargeable to Customer. If a transfer involves re- handling the goods, it will be subject to a charge. When goods in storage are transferred from one party to another through issuance of a new warehouse receipt, a new storage date is established on the date of transfer. Contractor reserves the right to move, at Contractor’s own expense, and upon notice sent by registered mail to Customer or to the last known holder of the negotiable warehouse receipt, any goods in storage from the Warehouse in which they may be stored to any other of Contractor’s Warehouses; but if Customer or holder takes delivery of such goods in lieu of transfer, no storage charge shall be made for the current storage month. Contractor may, without notice, move goods within the Warehouse in which they are stored. Except as otherwise provided in the receipt for goods accepted into storage, Contractor may, upon written notice to Customer and to any other person known by Contractor to claim an interest in the goods, require the removal of any goods thirty (30) days from the date the notice is received. Such notice shall be given by delivery in person or by registered letter addressed to the last known place of business or abode of the person to be notified. In the event goods may be about to deteriorate or may constitute a hazard to other property or to the Warehouse or persons, the time for removal may be any reasonable period less than thirty (30) days. Notices under this section shall be deemed received on the fifth (5th) day after the date the notice is mailed by certified or registered mail, return receipt requested.

23. Handling. The handling charge covers the ordinary labor involved in receiving goods at the Warehouse door, placing goods in storage, and returning of goods to the Warehouse door. Labor for unloading goods will be charged to Customer. Any additional expenses incurred by Contractor in unloading damaged goods will be charged to Customer. Unless Contractor has failed to exercise due care and diligence, Contractor shall not be responsible for demurrage, nor for delays in unloading inbound shipments, nor for delays in obtaining carriers for outbound shipments. When goods are ordered out in quantities less than in which received, Contractor may make an additional charge for each order or each item of an order.

Machinery Movers-Warehousing-Export Packing & Crating-Legal & Oversize Transportation.

24. Delivery Requirements. No goods shall be delivered or transferred except upon receipt by Contractor of complete instructions properly signed by Customer. However, when no negotiable receipt is outstanding, goods may be delivered upon instructions by telephone, but Contractor shall not be held responsible for loss or error occasioned thereby. When a negotiable receipt has been issued, no goods covered by that receipt shall be delivered or transformed on the books of Contractor, unless the receipt, properly endorsed, is surrendered for cancellation, or for endorsement of partial delivery thereon. If a negotiable receipt is lost or destroyed, delivery of goods may be made only upon order of a court of competent jurisdiction and the giving of a bond with sufficient sureties to be approved by the court. When goods are ordered out, a reasonable time shall be given Contractor to carry out instructions, and if Contractor is unable because of fire, acts of God, war, public enemies, seizure under legal process, strikes, lockouts, riots and civil commotions or causes beyond Contractor’s control to effect delivery before expired storage dates, the goods will continue to be subject to regular storage charges.

25. Extra Services (Special Services). Warehouse labor required for services other than ordinary handling and storage will be charged to Customer. Clerical labor for compiling of special stock statements, for reporting marked weights, serial numbers or other data from packages in store, or for the physical check of goods in store, or for handling transit billing, or other similar services, will be charged to Customer. Dunnage, bracing, packing materials, or other special supplies may be provided for Customer at a charge in addition to Contractor’s cost. By prior arrangement, goods may be received or delivered during other than usual business hours, subject to a charge. Customer shall be solely responsible for damages or other losses occurring while Customer’s goods or equipment are in transit and for obtaining any and all necessary insurance coverage for any such damages and losses.

26. Bonded Stores. A charge in addition to regular rates will be made for merchandise in bond. Where a warehouse receipt covers goods in U.S. Customs Bond, such receipt shall be void upon the termination of the storage period fixed by law.
27. Minimum Charges. A minimum handling charge per lot and a minimum storage charge per lot per month shall be assessed. A minimum monthly charge to one account for storage and/or handling will be made. This charge will apply also to each account in the event Customer has several accounts, each requiring separate records and billing.

28. Liability. Contractor assumes no liability for any loss or injury to the goods stored that could not have been avoided by the exercise of reasonable care required by law or a reasonably careful man. Goods are stored at Customer’s risk of loss for damage by acts of God, seizure or other acts of civil or military authority, insurrection, riot, strike, or enemies of the government, for loss or damage resulting from inadequate packaging or wear and tear, or from any cause not originating in the Warehouse or from any cause beyond Contractor’s control.

29. Goods that are subject to damage through temperature or humidity changes or other causes incident to general storage will be received in general storage only at Customer’s risk for such damage as might result from general storage conditions. Goods are not insured by Contractor for the benefit of the Customer against fire or any other casualty.

30. Indemnity. CUSTOMER SHALL INDEMNIFY AND HOLD HARMLESS CONTRACTOR, ITS DIRECTORS, OFFICERS, AGENTS, CONSULTANTS, EMPLOYEES AND OTHER AFFILIATES,FROM AND AGAINST ANY AND ALL CLAIMS, INCLUDING CLAIMS ASSERTED BY ANOTHER CUSTOMER OR A THIRD PARTY SUCH AS AN INSURER THROUGH SUBROGATION OR OTHERWISE, WHETHER ARISING IN TORT OR IN CONTRACT AND INCLUDING CLAIMS FOR QUANTUM MERUIT, THAT RESULT FROM THE CONDITION, WHETHER HAZARDOUS OR OTHERWISE, OF CUSTOMER’S GOODS OR EQUIPMENT STORED WITH CONTRACTOR OR OCCURRING DURING TRANSIT OF CUSTOMER’S GOODS OR EQUIPMENT.

31. AS A CONDITION OF DEPOSIT, IT IS CUSTOMER’S SOLE RESPONSIBILITY TO STABILIZE AND SECURE THE GOODS OR EQUIPMENT PRIOR TO DEPOSIT WITH CONTRACTOR. CUSTOMER’S OBLIGATIONS UNDER THIS PROVISION INCLUDE, BUT ARE NOT LIMITED TO, PAYMENT OF DAMAGES, CLEANING COSTS AND ATTORNEY FEES INCURRED IN ORDER TO ENFORCE THIS PROVISION OR IN DEFENDING A CLAIM CONTEMPLATED UNDER THIS PROVISION.

32.Limitation of Damages and Claims. Warehouse/Storage:
CONTRACTOR’S LIABILITY FOR DAMAGES TO WAREHOUSED
GOODS AND EQUIPMENT SHALL NOT INCLUDE ANY LIABILITY FOR CONSEQUENTIAL DAMAGES AND IS LIMITED TO THE LESSER OF: (1) THE COST OF REPAIR OR REPLACEMENT OF THE GOODS AND EQUIPMENT; (2) THE LIMITS OF CONTRACTOR’S INSURANCE COVERAGE FOR SUCH LOSS, PROVIDED, HOWEVER, THAT SUCH LIABILITY MAY ON WRITTEN REQUEST OF CUSTOMER WITHIN A REASONABLE TIME AFTER RECEIPT OF WAREHOUSE RECEIPT BE INCREASED ON PART OR ALL OF THE GOODS OR EQUIPMENT HEREUNDER, IN WHICH EVENT A MONTHLY CHARGE FOR SUCH ADDITIONAL INSURANCE WILL BE AGREED UPON IN WRITING BY THE PARTIES AND MUST BE PAID IN ADDITION TO
THE REGULAR MONTHLY STORAGE CHARGE. UNLESS OTHERWISE AGREED TO IN WRITING, THE LIMITATION ON LIABILITY APPLIES TO ALL GOODS AND EQUIPMENT STORED BY CUSTOMER WITH CONTRACTOR, WHETHER A SINGLE ITEM OR MULTIPLE ITEMS; CLAIMS BY CUSTOMER MUST BE PRESENTED IN WRITING WITHIN A REASONABLE TIME AND IN NO EVENT LONGER THAN THIRTY (30) DAYS AFTER DELIVERY OF THE GOODS. NO ACTION MAY BE MAINTAINED BY CUSTOMER AGAINST CONTRACTOR FOR LOSS OR DAMAGE TO GOODS COVERED HEREUNDER UNLESS COMMENCED WITHIN 12 MONTHS FOLLOWING DATE OF DELIVERY BY CONTRACTOR